The URL can be used to link to this page

Home My WebLink About19 Shell Drive Anderson quote 9.16.20Fronn: Bill Allen ballen@reriewalsne.com Subject: Renewal by Andersen Date: Sep 17, 2020 at 8:43:11 AM To: dmccaughin@comcast.net Dear Dave, I wanted to drop you a note to personally thank you for choosing Renewal by Andersen. I've spoken to Paul McLean about your window replacement project, and I'm sure you'll be happy with the selections you've made. Paul said he really enjoyed his visit with you. At Renewal by Andersen, we're committed to treating our customers the way we'd want to be treated. Our goal is to deliver "Red Carpet" service that exceeds your expectations. If you need any assistance beyond the typical questions you might ask Paul, please call or e-mail me any time. Again, thank you for the confidence you've placed in Renewal by Andersen. We promise to make your replacement experience a positive one. Sincerely, Bill Allen Vice President of Sales ED Renewal by Andersen I Southern New England OCT 01 2020 o: 401 4500711 w: RenewalByAndersen.com YARMOUTH Renewal by Andersen sells, installs, and services energy- efficient replacement windows and patio doors resulting in beautiful homes and delighted homeowners. Our Company Mantra: mufrill Renewal l bAndersen. -: ' WINDOW REPLACEMENT an AjidetsesiConinany a Rte newaldha: Renewal By Andersen of5outhern New England byAndersen. Legal Name: Southern New England windows, LLC RI #36079, MA #173245, CT #0634555, Lead Firm #1237 10 Reservoir Rd I Smithfield, RI 02917 Phone: 401-349.1384 1 Fax: 401-633-6602 1 sales0renewalsne.com WINDOW pE LAC EMEMT �RECEAVIED OCT 01 2020 YARMOU-fH.... Dave M[Caughln 19 Shell Dr Yarmouth Port, MA 02675 H:(774)994.8150 C: (617)347-4353 Thank you for your order Please find, enclosed for your convenience, the contents of your agreement with Southern New England Windows, LLC d/b/a. Renewal By Andersen of Southern New England Table of Contents Agreement Document and Payment Terms ............................................. 2 Itemized Order Receipt........................................................... 3 Noticeof Cancellation............................................................5 Terms and Conditions of Sale.......................................................G Sales Cost Savings Program (SCSP) ..... . . . . . . ...... . . . . . . ........................... g Lead -Safe Form (CT & MA) ...................... ................................. 9 Important Project Information.....................................................10 HistoricAddendum.............................................................12 Price Presentation Discounts...................................................... 13 UPDATED: 09/16/20 Pagel/13 Renewal Agreement Document and Pa byAndelsen, r _ db a: Renewal By Andersen of Southern New England Legal Name: Southern New England Windows, LLC OCTy ++�+ RI #36079, MA #173245, CT #0634555, Lead Firm #1 37 1 i 1 2020 w,xaow ter ue[IRENT 10 Reservoir Rd I Smithfield, RI 02917 Phone: 401-349-1384 1 Fax: 401-633-6602 1 sales®renewalsne.cor6 41r%Uiyj-� Buyer(s) Name: Dave McCaughin Buyer(s) Street Address: 19 Shell Dr , Yarmouth Port, MA 02675 Primary Telephone Number: (774)994-8150 Primary Email: dmccaughin@comcast.net ve McCaughin Shell Dr rmouth Port, MA 02675 (774)994-8150 (617)347-4353 Contract Date: 09/16/20 Secondary Telephone Number: (617)347-4353 Secondary Email: Buyer(s) hereby jointly and severally agrees to purchase the products and/or services of Southern New England Windows, LLC d/b/a Renewal By Andersen of Southern New England ("Con tractor"), in accordance with the terms and conditions described in this Agreement Document and Payment Terms, any documents listed in the Table of Contenrs, and any other document attached to this Agreement Document, the terms of which are all agreed to b the parties and incorporated herein by reference (collectively, this "Agreement"). Buyer(s) hereby agrees to sign a completion certificate after Contractor has completed all work under this Agreement. Total job Amount: $18,514 Deposit Received: $6,170 Balance Due: $12,344 Amount Financed: $0 By signing this Agreement, you acknowledge that the Balance Due, and the Amount Financed must be made by personal check, bank check, credit card, or cash. Estimated Start: 10 to 12 weeks Method ofPayment: Cash/Check We schedule installations based on the dare of the signed contract and secondarily on the dare in which we complete the technical measurements. The installation date chat we are providing at this rime is only an estimate. We will communicate an official date and time at a later date. Rain and extreme weather are the most common causes for delay. Notes: Taxes included ; $6170. Dep. in check ; $50. Permit in check Buyer(s) agrees and understands that this Agreement constitutes the entire understandings between the parties and that there are no verbal understandings changing or modifying any of the terms of this Agreement. No alterations to or deviations from this Agreement will be valid without the signed, written consent of both the Buyer(s) and Contractor. Buyer(s) hereby acknowledges that Buyers) 1) has read this Agreement, understands the terms of this Agreement, and has received a completed, signed, and dated copy of this Agreement, including the two attached Notices of Cancellation, on the dare first written above and 2) was orally informed of Buyer's right to cancel this Agreement. NOTICE TO BUYER: Do not sign this contract if blank. You are entitled to a copy of the contract at the time you sign. YOU, THE BUYER, MAY CANCEL THIS TRANSACTION AT ANY TIME NOT LATER THAN MIDNIGHT OF 09/19/2020 OR THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION, WHICHEVER DATE IS LATER. SEE THE ATTACHED NOTICE OF CANCELLATION FORM FOR AN EXPLANATION OF THIS RIGHT. Legal Name-, Southern New England Windows, LLC db -j: RcrKr6�t7� derscn ofSou rhern New England Buycr(s) /--Z- �� A wvo_ Signature of Sales Person Paul Mclean Print Name of Sales Person Signature Dave McCaughin Print Name Signature Print Name UPDATED: 09116120 Page 2 113 Renewal Itemized Order Receipt R��E�VED byAndersen. dba: Renewal B Andersen of Southern New England — Y $ ave McCaughin Legal Name: Southern New England Windows, LLC OCT 101 2020 1 Shell Dr RI #36079, MA #173245, CT #0634555, Lead Firm #1237 rmouth Port, MA 02675 winnow ac uC..... 10 Reservoir Rd I Smithfield, RI 02917 YARMOUTH H (774)994.8150 Phone: 401-349-1384 1 Fax: 401.633-6602 1 sales@renewalsne.com OLD KIN ' H1 HWAY 1617}347-4353 ID#: ROOM:. DETAILS: Misc: Misc, THANK YOU!, As a reminder, it is the customer's responsibility to do any painting, staining or touch up work after installation. We appreciate your business and look forward to exceeding your expectations. Misc: Misc, PERMIT, Customer has paid for Renewal by Andersen to secure a building permit for their project. Permit fees are non-refundable once Renewal By Andersen applies for a permit. 101 living Window: Casement, Double, Vented, EJ Frame, Exterior White, Interior White, Glass: All Sash: High Performance, No Pattern, Hardware: White, Screen: Fiberglass, Full Screen, Grille Style: No Grille, Misc: NEW Int. STANDARD Casing - Pine, 2.5" or 3.5% colonial or clamshell only or 1x4 flatstock. Picture frame or Traditional, stool and apron., NEW Ext. Casing - Fibrex Brickmould, FULL FRAME ONLY. Picture Frame or Traditional, Includes sill nose. 102 living Window: Casement, Double, Vented, EJ Frame, Exterior White, Interior White, Glass: All Sash: High Performance, No Pattern, Hardware: White, Screen- Fiberglass, Full Screen, Grille Style: No Grille, Misc: NEW Int, STANDARD Casing - Pine, 2.5" or 3.5", colonial or clamshell only or 1x4 flatstock. Picture frame or Traditional, stool and apron., NEW Ext. Casing - Fibrex Brickmould, FULL FRAME ONLY. Picture Frame or Traditional, Includes sill nose. UPDATED: 09/16/20 Page 3 r 13 Renewal Itemized Order Receipt byAndersen. d6a: Renewal B Andersen of Southern New England Y S Dave McCaughtn ��Kinee Legal Name: Southern New England Windows, LLC 1■ 19 Shell or %� RI #36079, MA #173245, CT #0634555, Lead Fir QIP Yarmouth Port, MA 02675 WINooW nc ucrM4NT 10 Reservoir Rd I Smithfield, RI 02917 p 1 H: {774}994-8150 Phone: 401-349-1384 1 Fax: 401-633-66021saies®renewalsne.c OCT I V y Zo?0 C: (617)347-4353 Y At�fv1G� i E' s P.ROOM: 103 kitchen Window: Casement, Double, Vented, EJ Frame, Exterior White, Interior White, Glass: All Sash: High Performance, No Pattern, Hardware: White, Screen: Fiberglass, Full Screen, Grille Style: No Grille, Misc: NEW Int. STANDARD Casing - Pine, 2.5" or 3.5", colonial or clamshell only or 1x4 flatstock. Picture frame or Traditional, stool and apron., NEW Ext. Casing - Fibrex Brickmould, FULL FRAME ONLY. Picture Frame or Traditional, Includes sill nose. 104 kitchen Window: Casement, Double, Vented, EJ Frame, Exterior White, Interior White, Glass: All Sash: High Performance, No Pattern, Hardware. White, Screen: Fiberglass, Full Screen, Grille Style: No Grille, Misc: NEW Int. STANDARD Casing - Pine, 2.5" or 3.5", colonial or clamshell only or 1x4 flatstock. Picture frame or Traditional, stool and apron., NEW Ext. Casing - Fibrex Brickmould, FULL FRAME ONLY. Picture Frame or Traditional, Includes sill nose. 105 laundry Window: Casement, Double, Vented, EJ Frame, Exterior White, Interior White, Glass: Ail Sash: High Performance, No Pattern, Hardware: White, Screen: Fiberglass, Full Screen, Grille Style: No Grille, Misc: NEW Int. STANDARD Casing - Pine, 2.5" or 3.5', colonial or clamshell only or ix4 flatstock. Picture frame or Traditional, stool and apron., NEW Ext. Casing - Fibrex Brickmould, FULL FRAME ONLY. Picture Frame or Traditional, Includes silt nose. WINDOWS: 5 PATIO DOORS: 0 SPECIALTY: 0 MISC: 2 TOTAL $18,514 Renewal by Andersen is ronimirred to our crestoneers'rafery by $EPA 4 r complying with rhe rules and lead -safe work pracriees specified by the EPA. UPDATED: 09/16!20 Page 4 / 13 Renewal Notice of Cancellation ersen. byAnd",7 dba, Renewal By Andersen of Southern Now England Legal Name: Southern New England Windows, LLC RI #36079, MA #173245, CT #0634555, Lead Firm #1 10 Reservoir Rd I Smithfield, RI 02917 Phone: 401-349-1384 1 Pax: 401-633-6602 l sales@renewalsne,cam ECC !tl E OCT 01 `re?a Dive McCaughin 19�Shell Dr CING'S HIGHWAY 3Tmouth Port, MA 02675 H: (774)994-8150 C: (617)347-4353 You, the buyer(s) may cancel this transaction at any time prior to midnight on 09119/2020 or the third business day after the date of this transaction, whichever date is later, NOTICE OF CANCELLATION Date of Transaction: 09116120. You may cancel this transaction, without any penalty or obligation, before midnight on 09/19/2020 or the third business day after the date of this transaction, whichever date is later. If you cancel, any property traded in, any payments made by you under the Contract or Sale, and any negotiable instrument executed by you will be returned within 10 business days following receipt by the Seller of your cancellation notice, and any security interest arising out of the transaction will he canceled. If you cancel, you must make available to the Seller at your residence, in substantially as good condition as when received, any goods delivered to you under this Contract or Sale; or you may, if you wish, comply with the instructions of the Seller regarding the return shipment of thegoods at the Sellers expense and risk. If you do make the goods available to the Seller and the Seller does not pick them up within 20 days of the date of your Notice of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make thegoods available to the Seller, or if you agree to return the goods to the Seller and fail to do so, then you remain liable for performance of all obligations under the Contract. To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice or any other written notice, or send a telegram, to: dba: Renewal By Andersen of Southern New England Legal Namc: Southern New England Windows, LLC 10 Reservoir Rd Smithfield, RI 02917 Phone: 401-349-1384 Fax: 401-633-6602 Email: salesrenewalsne.com NOT LATEPHAN MIDNIGHT OF 09/19/2020 OR THE THIRD BUSINESS DAYAFTERTHE DATE OF THIS TRANSACTION, WHICHEVER DATE IS LATER. I HEREBY CANCEL THIS TRANSACTION Buyer Signature Date NOTICE OF CANCELLATION Date of Transaction: 09116120. You may cancel this transaction, without any penalty or obligation, before midnight on 09/19/2020 or the third business day after the date of this transaction, whichever date is later. If you cancel, any property traded in, any payments made by you under the Contract or Sale, and any negotiable instrument executed by you will be returned within 10 business days following receipt by the Seller of your cancellation notice, and any security interest arising out of the transaction will be canceled. If you cancel, you must matte available to the Seller at your residence, in substantially as good condition as when received, any goods delivered to you under this Contract or Sale; or you may, if you wish, comply with the instructions of the Seller regarding the return shipment of thegoods at the Sellers expense and risk. If you do make the goods available to the Seller and the Seller does not pick them up within 20 days of the date of your Notice of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make thegoods available to the Seller, or if you agree to return the goods to the Seller and fail to do so, then you remain liable for performance of all obligations under the Contract. To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice or any other written notice, or send a telegram, to: db a: Renewal By Andersen of Southern New England Legal Name: Southern New England Windows, LLC 10 Reservoir Rd Smithfield, RI 02917 Phone: 401-3494384 Fax. 401-633-6602 Email: salcsc@rcnewalsne.com NOT LATER THAN MIDNIGHT OF 09/19/2020 OR THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION, WHICHEVER DATE IS LATER. I HEREBY CANCEL THIS TRANSACTION Buyer Signature Date UPDATED: 09/16/20 Page 5/13 Renewal Terms and Conditions of SaFREEIVEDbyAndersen. dba: Renewal Sy Andersen ol'Southarn Ncw EnglandDave McCaughan �4�i Legal Name: Southern New England Windows, LLC19 Shell Dr +00*' RI #36079, MA #173245, CT #0634555, Lead FirmYarmouth Port, MA 02675 wing Ow NE LACEWXI l0 Reservoir Rd l Smithfield, RI 02917 H: (774)994.8150 Phone: 401.349-1384 1 Fax: 401-633-6602 1 saleserenewalsne.co AY C: (617)347-4353 I", "my," and "me" means each person who signs this Agreement as a buyer. "Contractor" means Southern New England Windows," "LLC d/b/a Renewal by Andersen of Southern New England. "We" and "us" mean both the buyer, or buyers if more than one, and the Contractor. Renewal by Andersen of Southern New England is an authorized and independent dealer of Renewal by Andersen. You are entering into a contract with Renewal by Andersen of Southern New England. I agree and understand that if I finance the work with Contractor or a third party, my separately provided financing documents will include the number of monthly payments and the amount of each payment, including any finance charge." Warranties/Intended Use: I understand that Andersen Corporation ("Andersen') is providing me with a warranty in connection with my purchase. I understand that I should read Andersen's written warranty for complete details of my warranty coverage and chat the Andersen warranty is available for my complete review before I sign this Agreement. I understand that the Andersen warranty will not be effective or enforced while a balance due remains on this Agreement. Contractor's Promises: Contractor promises to perform all work in a professional manner and within industry standards. Contractor will remove and transport away from the premises any debris and waste materials that are generated by Contractor. Contractor shall obtain all building permits for the work to be performed under this Agreement. My Promises: I promise to Contractor that (a) I will provide Contractor with reasonable access to my property, including access to electrical outlets; (b) I will be responsible for preparation, moving, and reinstalling of any materials, personal property, cars, or equipment as may be needed for Contractor to perform its work; (c) The walls and surfaces upon which the work is to be performed are sound and suitable for the work being performed; (d) When the work is "substantially complete", I will pay Contractor the balance due under this Agreement. I understand that "substantially complete" means the work has been materially finished and is functional as intended; (e) In the event chat I disagree with Contractor that the work is substantially complete, I agree that I will not withhold more than 10% of the Total Job Amount; and (f) If taxes are necessary to complete the work, I will pay them unless the law requires Contractor to pay them. Contractor may place a small advertising sign in my yard at the time of install. Measurements: 1 understand that dimensions referred to in this Agreement are estimates and used only for arriving at the Total Job Amount. I understand that the actual measurements will be determined during a follow-up visit by a qualified measurement technician. I understand that if Contractor must make changes to the estimated measurements, I will have to sign an addendum to this Agreement. Late Cancellation: l understand that I have 3 business days to cancel this Agreement, as described on the front page of this Agreement. I understand that if I want co cancel this Agreement after those 3 business days, Contractor does not have to allow that. I understand that if Contractor does let me cancel, however, I will have to pay to Contractor a late cancellation fee equal to 25% of the Total Job Amount for Contractor's labor, administrative, and material costs. Delay/Unknown Conditions: I understand char if Contractor determines that Contractor cannot perform the work according co Contractor's normal professional standards, then Contractor can cancel this Agreement, notify me in writing of the cancellation, and return my money to me. I understand that some of the things that could cause Contractor to cancel this Agreement would be incorrect pricing, unforeseen structural defects, or unknown pre-existing conditions to my property. I understand that Contractor is not responsible for structural or other defects in my property, and chat Contractor's products do not cure those types of problems. I also understand that the work could be delayed by events that Contractor does not control, and that is acceptable to me. Some of the things that could cause the work to be delayed would be acts of God, labor strikes, inclement weather, material shortages, my inability to qualify for or obtain Financing, delays by local government authorities in issuing or otherwise approving inspections, permitting, or other required authorizations for the work, Late Payment/Default- I agree that if I do not pay Contractor any of the money owed when it is due, I can be charged a late fee of 1.5% on the amount owed for each month the money is owed and not paid. I also agree that if I default on my promises under this Agreement, and Legal Name: Southern New England Windows, LLC dbar Reryelva] y t dersen of Southern Ncw England Buyer(s) Signature of Sales Person Paul McLean Prise Name of Sales Person Signature Dave McCaughin Print Name Signature Print Name UPDATED: 09/16/20 Page 6 / 13 Renewal Terms and Conditions of Sa ' ECOVE Andersen. dbai Renewal By Andersen of Southern New England OCT1 1G2� Dave McCaughin r U W Legal Name: Southern New England Windows, LLC L1237 19 Shetl Dr %�� RI #36079, MA #173245, CT #0634555, Lead Firm YAB 1 -jTH Yarmouth Port. MA 02675 WINDOW NE LA6[NEXr 10 Reservoir Rd I Smithfield, RI 02917 D KING' IiIGHVVAY K: (774)994.8150 Phone; 401-349.1384 1 Fax: 401-633-6602 1 salesGrenewalsnexom C: (617)347.4353 Contractor hires an attorney to enforce this Agreement, I will pay Contractor its reasonable legal Fees and related costs or expenses, as long as it is legal for me to do that. I agree and understand that in the event that I do not pay Contractor any of the money awed when it is due, Contractor may have a claim against me, which may be enforced against my property in accordance with the applicable lien laws. I also understand that if I finance the work with Contractor or a third parry, my separately provided financing documents may include a security interest. I understand that I should read those documents closely. "I agree and understand that I will assert a dispute, claim, or controversy (hereafter referred to as a "Claim") arising under or relating to this Agreement only on behalf of my own self and that I will not assert a Claim on behalf of, or as a member of, a class or group in either an arbitration proceeding, a private attorney general action, or in any other forum or action. If a court determines that this specific paragraph is not fully enforceable, the court's determination shall be subject to appeal. This paragraph does not apply to any lawsuit or administrative proceeding filed against Contractor by a state or federal government agency. Interpretation of This Agreement, I agree that this Agreement will be enforced under the laws of the state where the work is being performed. If any part of this Agreement is determined to be invalid or illegal, then I agree chat die rest of this Agreement will still be valid and enforceable. We both understand that this Agreement and any attachments, make up the entire understanding between us about the work Contractor is doing. Thcre are no other oral or written agreements or representations on which we are relying. We both agree that any change to this Agreement must be in writing and signed by both of us. The paragraph headings contained in this Agreement are for convenience only and will not affect the meaning or interpretation of this Agreement. (Connecticut Sales Only) The owner(s) of the home improvement contractor is or has been a shareholder, member, partner, or owner of the Fallowing corporations, limited liability companies, partnerships, sole proprietorships or other legal entities that have been a home improvement contractor during the previous five years: None." (Massachusetts Sales Only) Any deposit required under this Agreement to be paid in advance of the commencement of work shall not exceed the greater of one-third of the total contract price or the actual cost of any materials or equipment of a special order or custom made nature, which must be ordered in advance of the commencement oFwork, in order to assure that the project will proceed on schedule. No final payment shall be demanded until this Agreemcnc is completed to the satisfaction of the parties. In Massachusetts, all contractors and subcontractors must be registered by the administrator of the board of building regulations and standards and any inquiries about a contractor or subcontractor relating to a registration should be directed to: Office of Consumer Affairs and Business Regulation, Ten Park Plaza, Suite 5170, Boston, Massachusetts 02116, Telephone: (617) 973- 8700. In Massachusetts, the contractor is responsible for applying for and obtaining any and all necessary permitting. Homeowners who secure their own permits will be excluded from the guaranty fund provisions of Massachusetts law. (Rhode Island Sales Only) The contractor and/or subcontractors or material persons may file a lien in accordance with the Rhode Island Mechanics Lien Act, chapter 28 of tide 34. (Rhode Island Sales Only) During the term of this Agreement, Contractor shall maintain public liability and property damage insurance covering the work of not less than $500,000 combined single limit, bodily injury and property damage and workers' compensation insurance as required under chapter 29 of title 28. Condensation and Environmental Conditions: Condensation, which can form on or within walls, siding, tiles, or other surfaces results from pre-existing conditions in a home and internal or external temperatures. Reducing the humidity in a home will often remedy any condensation problems. I agree that Contractor is not responsible for condensation or existing or developing spore or mold growth, which can be the result of condensation. Ugal Name: Southern New England Windows, LLC dba; RcrKv y i dcrscn of Southern New England Buyer(s) (� /--Z- 4� A � Signature of Sales Person Paul McLean Print Name of Sales Person Signature Dave McCaughin Print Name Signature Princ Name UPDATED: 09/16/20 Page 7 / 13 Renewal Sales Cost Savings Program (SCSP) b Andersen. dba: Renewal By Andersen of Southern New England Dave McCaughin .14 "..� Legal Name: Southern New England Windows, LLC 19 Shell Dr RI #36079, MA 8173245, CT #0634555, Lead Firm #1237 Yarmouth Port, MA 02675 10 Reservoir Rd I Smithfield, Ri 02917 H: (774)994.8150 Phone: 401-349-13841 Fax: 401-633.5602 1 sales®reroewalsrze.com C: (617)347-4353 To: All Sales Personnel RECEIVED Date: September 1, 2005 LOUDKIN '1 2020 From: Matthew Ester - CEO/ COO Renewal by Andersen of Southern New England UU I tt Re: Sales Cost Savings Program (SCSP) HIGHWM At Renewal by Andersen, we are always looking for ways to increase value, and we've found a new way ro lower costs to our customers. The majority of customers that we meet love Renewal by Andersen and are comfortable enough to award us the project on the initial visit. For a variety of reasons, some customers feel they need time to "chink it over" for a day or two before placing the order. This requires a second visit. We are happy to visit our customers as many times at it taker to earn their business. However, when the consumer makes -a buying decision on the first visit, the sales cost of additional visits is saved and we are happy to pass that savings on to our customers. Please keep in mind, the savings are only realized during the initial visit. Please keep in mind, the savings are only realized during the initial visit. Best Regards, Matrhew Ester CEO/COO, Renewal by Andersen By signing below I acknowledge receipt of the initial visit, sales cost savings plan. As a way of saying thank you, this savings will be included in all your future orders. Lxgal Dame: Soutbecn New England Windows, LLC dba: ReryetvaI y dersen of Southern New England Euyer(s) Signature of Sales Person Paull McLean Print Name of Sales Person Signature Dave McCaughan Print Name Signature Print Name UPDATED: 09/16/20 Page 8 / 13 Renewal Lead -Safe Form (CT & MA) byAndel"sen, dba: Renewal By Andersen of Southern New England pave M[Caughin Legal blame: Southern New England Windows, LLC 19 Shell Or RI #36079, MA #173245, CT #0634555, Lead Firm #1237 Yarmouth Port, MA 02675 wixgo� RF LACEME.. 10 Reservoir Rd I Smithfield, Rl 02917 H: (774)994-8150 Phone: 401-349-1384 1 Fax: 401-633-6602 1 salesCrenewalsne.com C: (617)347-4353 Lead Safe Work Pamphlet Receipt and Lead Testing Permission Form REC-EP ED OCT 01 2020 Pamphlet Receipt YARMOU_^ WA) I have received a copy of The lead hazard information pamphlet informing me of the potential risk of the lead hazard exposure from renovation activity to be performed in my dwelling. I received this pamphlet before the work began. Permission to Test I confirm if my house was built between the years of 1940 and 1977, 1 understand and give permission to have my house tested for Lead Paint at time the measure technician comes out to take final measurements. I understand that the if the test does show the presence of lead paint, that the firm performing the renovation will be required to use the lead -safe work practices required by EPA's Lead -Based Paint Renovation, Repair, and Painting Rule. I also understand that there is no added charge for using the lead safe work practices. By signing below, I hereby agree to the terms and conditions above. Legal Name: Southern New England Windows, LLC dba: Rcrye}�alt clerscn of Southern New England Buyer(s) Signature of Sales Person Paul McLean Print Name of Sales Person Signature Dave McCaughin Print Name Signature Print Name UPDATED: 09/16/20 Page 9 / 13 Renewal Important Project Information byAndersen. dba: Renewal By Andersen of Southern New England Dave McCaughin Legal flame: Southern New England Windows, LLC 19 Shell Dr RI #36079, MA 0173245, CT #0634555, Lead Firm #1237 Yarmouth Port, MA 02675 w�xoow xr uc[Mrxi 10 Reservoir Rd I Smithfield, Ri 02917 H: (774)994.8150 Phone: 401-349-1384 1 Fax: 401-633-6601 1 sales®renewalsne.com C. (617)347-4353 .—Z—!rrmik ll CUSTOMER RESPONSIBILITIES OCT 01 2020 POSSIBLE GLASS LOSS FOR WINDOWS AND DOORS YAHNiOUTf-1 Customer has been made aware of the possible glass loss that occurs with the installation of replacement '0tt0vK1NG'S H1GHV1 POSSIBLE GLASS LOSS FOR BAY AND BOW WINDOWS Customer acknowledges acceptance of substantial glass loss due to the engineering of the frame to properly support the weight of the new unit. It is recommended when purchasing a bow window to replace the existing unit with one less section. For example, a 5 section bow should be replaced with a 4 section bow to help offset glass loss. PAINTING/STAINING RENEWAL BY ANDERSEN DOES NOT PERFORM ANY PAINTING OR STAINING ON ANY WINDOWS, DOORS OR TRIM. In order to provide you with the best finished product, our installers will not prefill nail holes. These tasks will be completed during the painting/staining process. It is your responsibility to coordinate and pay for all painting and/or staining after the windows are installed, including any new interior stops (replaced as needed) which is a small interior piece of wooden trim removed or installed during the installation of the windows. ENLARGING, WIDENING OR NEW OPENINGS Renewal by Andersen does not have the licensing to perform electrical or plumbing work, nor will the company be held liable for the removal or relocation of any electrical and/or plumbing that is discovered inside of the wall during the installation. If discovered, Renewal by Andersen will leave the opening scaled from exterior elements and notify the customer to discuss your responsibilities in getting said electrical and/or plumbing moved. Once electrical and/or plumbing is moved customer will call Renewal by Andersen to schedule the installation of the balance of the project. EXTERIOR ACCESS TO OPENINGS Customer must provide reasonable access to the exterior of each opening to perform the proper exterior installation and weather proofing guidelines. This may require some shrub and/or tree limbs to be trimmed back so an installer can have access with a ladder to the exterior of an opening. FURNITURE AND DECORATIONS We ask that you remove any furniture that may block access to the windows or door openings. We ask that you remove the pictures from the walls being worked on and any decorations that are in the work area before work begins. This will greatly reduce the likelihood of any accidental damage to personal property. WINDOW COVERINGS Please remove all blinds, shades or shutters before we arrive. Should you need assistance removing and reinstalling your existing blinds, shades or shutters, we offer that as a fee based service, but we are not responsible for the fit or operation of the blinds, shades or shutters. We also assume no liability for any new blinds or shutters: that includes fit, measuring and installation. All of these processes should be handled by a professional window treatment company. Legal Na -mc; Southern Ncw England Windows, LLC dba: Rcrlewal y dersen of Southern Nmy England Buyer(s) fi �1--2- ��'A wvi,;- Signature of Sales Person Paul McLean Print Name of Sales Person Signature Dave McCaughin Print Name Signature Print Name UPDATED: 09/16/20 Page 101 13 Renewal important Project Information byAndersen. dba: Renewal By Andersen of Southern New England Dave McCaughin Legal Name: Southern New England Windows, LLC 19 Shell Dr RI #36079, MA #173245, CT #0634555, Lead Firm #1237 Yarmouth Port, MA 02675 w,Aoow AE IMCEMENT 10 Reservoir Rd I Smithfield, RI 02917 s� rH (i<4y894 8150 Phone: 401.349-1384 1 Fax: 401-633-6602 1 salesefrenewalsnexom RECEI�( {i 7 4i..4353 I�.� i AIR CONDITIONING UNITS I OCT 0 1 2020 Owner is responsible for the removal and reinstallation of any AC units and brackets. YAR1vl0i1-1 t7 ALARM SYSTEMS • „" „� . ` Owner is responsible for the removal and reinstallation of any existing alarm systems. PLEASE CONTACT ALARM COMPANY FOR DETAILS. PETS Because not all pets react favorably to the excitement of the construction process, we ask that you keep all of your pets confined during the time we are working on your home. `This should keep them from becoming stressed, accidentally escaping or possible injury. SECOND AND FINAL PAYMENT The second payment is due at start of installation and final payment is due at the completion of the installation. The check is made payable to Renewal by Andersen of SNE. You may hand the check to the installer who will then bring the check into the office. IFyou have financed your project, there will be a finance sign off form made available to you by the installation crew. Credit Card payments can only be accepted for one third of the total project cost. WHAT IS INCLUDED Renewal by Andersen will insulate, caulk and seal windows with our 3 —point defense system to prevent water and air infiltration VISIBLE ROT RbA of SNE will replace or repair VISIBLE rot on sills or exterior casings. NOT INCLUDED Any UNSEEN, HIDDEN or STRUCTURAL rot, that will be addressed at time of discovery, HAUL AWAY/DISPOSAL & CLEAN UP RbA of SNE will clean up all job related debris, including old windows and storms, and will vacuum nightly. FINISH PAPERWORK RbA of SNE will presenr customer with maintenance manuals and warranty documents upon completion of project and payment in full. PERMITS The fee for any and all required building permits is to be paid by the customer to Renewal by Andersen. Renewal by Andersen will secure any and all required building permits. On occasion, an outstanding customer bill with the municipality will prohibit Renewal by Andersen from securing a permit. When applicable, contractor will notify customer and it is up to the customer to pay any owed balance to the town so contractor can secure the proper permirs prior to installation. We ask that the customer close out the permit, after installation, with the issuing municipality when necessary. ALL CURRENT PROMOTIONS AND DISCOUNTS HAVE BEEN APPLIED TO THIS AGREEMENT ANY FUTURE DISCOUNTS OR SALES CANNOT BE APPLIED AT A LATER DATE. Legal Name: Southern New England Windows, LLC dba: RedetraalA.3y�nderscn ofSouthern New England X Signature of Sales Person Paul McLean Print Name of Sales Person Buyer(s) Z� A WIN -- Signature Dave McCaughin Print Name Signature Print Name UPDATED: 09/16/20 Page 11 / 13 Historic Association Contract Addendum RE: Historic Home Owner Association Approval 1 RECFIVF 0 C T 01 2020 YAnivwu i h Dear Customer: Thank you for your business and our priority is getting your installation started as soon as possible. In order to expedite that process, we will need your help on a few items regarding the historic committee approval. We will need you to work on getting approval for your project from the historic board. Your project manager will be able to assist you with this process but most boards prefer dealing with the residents directly versus the contractor. That being said here are two things that we will need: 1) Your historic board will need to approve the project with the details as listed in your agreement. We recommend submitting the "Itemized Order Receipt" pages to have full disclosure of the scope of work proposed. 2) Once the project is approved we will need you to send a copy of the approval notice to orderprocessing(aa,renewalsne.coin . Please contact your Project Manager once this email has been sent to notify us and we will diligently get to work for you. If you need any assistance, contact your Project Manager directly. We look forward to helping you with your installation. Keep in mind that each day it takes to receive your approval will delay the installation time reflected on your contract by the same number of days. Please let us know what we can do to assist in your historic approval. Renewal Price Presentation Discounts byMdersen, dba: Renewal By Andersen of southern New England F4 Legal Name: 5outhern New England Windows, LLC 10i RI #36079, MA #173245, CT #0634555, Lead Firm 41237 WrRUUW RE LLCEYEN7 10 Reservoir Rd 15mithfield, RI 02917 Phone: 401-344-1384 1 Fax: 401-633 -6602 1 sales0renewalsne.com Dave M[Caughin 19 Shell or Yarmouth Port, MA 02675 H: (774)994-8150 C: (617)347-4353 PROJECT PRICE BEFORE DISCOUNTS S23,142 INDIVIDUAL SAVINGS BASED ON 5 UNITS Advertised Offer 20% Off Project OCT 01 2020 Savings: Hrswiv� I $4,628 D KIN HIGHWAY UPDATED: 09/16/20 Page 13 / 13 s Rt -CE-1 VI�[l 0 C I 01 2020 QLD YARMOUTH KINO'8 HIGHWAY 1� GCEIVED O C r 01 2020 YARMOji-�-1 CEI M EV OCT 0 1 2020 YARMOUTH RECOI ED OCT o 1 2020 rrli ,Ak)LjFri