The URL can be used to link to this page

Home My WebLink About80 Mattakese Rd Unit 5 - builidng permit solar wolfONE & TWOFAMILY ONLY. BUILDING PERMIT Town of Yormouth BuildlnS DePartmetrt 1146 Route 28, Soutil Yarmouth, MA 02664-4492 508-398-2231 ext. t26t Fax 508-398-0836 Massachusctts Stete Building Code, 780 CMR Building Permil Application To Constt'uct, RePai\ Renol)ate A' Demolish a One- or Two-Family Dwelling This Section For OIEcial Use Only Date Applied: BUILDING DEPA By TMENT 2 Building Offi cial (PliolName) SECTION 1r SITE INTORMATION 1.2 Assessors Msp & Porcel Numbers Pa.cclNnmbcrMap Numbcr l.l Property Addrei!: 80 MATTAKESE RD UNIT 5 W. YARMOUTH, MA 02673 1.4 Property Dimensions: Lot tuca (sq ft)Frodtagc (ft)ZoniryDistrict Proposcdusc 1.5 Brilding Setback (ft) Sidc Yards Rear YardFront YaId Providcd Requircd PlovidedRcquircdProvidedRequired Check if l-7 Flood Zone lnformation:Zane. Outside Flood Zonc? 1,8 Sewrgc Disposal Syst.m: Municipal tr On sitc tseel 1.6 WaterSupply: (M.G.L c.40,I5a) PublicB Privatc E SECTION 2: PROPERTY OWNf,RSfmt APR 25 IPING DEI AO MATTAKFSF RN UNIT 5 W YARMOI.ITH MA 02673 No. ard Strca Tclcphonc 617 58 Name (Print)City, Statc, ZIP Email JFANTONELLI 21 Ownerr ofRecord: JOE ANTONELLI SECTION 3: DFSCRIPTION OF PROPOSED WORK! (check all that appty) New Constsuction O Existing Building tr Owner-Occupied tr Repairs($ tr Alteralion(s) tr Addition tr Demolition tr Accessory Bldg. tr Number of Urits SOLAROther tr S Brief Desuiptioo of Proposed W ROOFTOP SO INSTALLA ONTI OF 24 SOLAR PANELS TO TOTAL A8O4 KW SYS IEM WI IH A SMAIT I ME IEH SOCKE I SECTION 4: ESIIMATED CONSIRUCTION COSTS Item Estimated Costs and Materials Official Use Only L Building $ rzlsl.ro 2. Etcckic.al $ $2s 60 3. Plumbing $ 4. Mcchanical (IIVAC)$ s 6. Total Project Cost:$ zoazt tr StaDdard City/Tovn Applicatioo Fec O To{al Project CosC GtEm 6) x Eulriplicr _ x Check No- Chcck AEourr C€lh A.Eolmt: Tofal All Fees: $ hdicatc how fec is dctcrmincd: tr Paid iD FUU tr OubtandiEg Balanc€ Due 2. OtherFcee: $_ Lin: [.;'li Il N 022 RiM UAD 10 'Builditrg Pemit Number: ( ED Signahl.c l.la Is this arl accapted street? yes no 1J Zolliog Information: 5. Mccbarical (Firc Supprcssio[) 1. Building Permit Fee: $ib_!_ SECTION 5: CONSTRUCTION SER.I/ICIS Llc=ose Numbcr List CSL Typc (s.G bclow) Erpindon Dr- u cs-087491 2-19-2024 Typ"D6c.iptioq U U !o 15 000 qu. ft. R Rcsr.ictcd l&2 D M RC Roofi ws Wiadow atrd S Solid Fucl Burniog Appliaoces i Iosulation 5.1 ConstructioD Sup.rvisor LiceNe (CSL) Ted Strzelecki EmBil address 508-538-9445 oPerations@solarwolfenergy.com CiV/Toyn, Sratc, ZIP NaDc ofCSI Hold.r 582 Wauwinet Road No. 6nd Srrccr Barre, MA 01005 D Dcmolitioo 5.2 Registered Home ImproycEent Contractor (IIIC) Solar Wolf Energy 508-538-9445cZDe N6lnc or HIC RcEistrant NamE noton Street - No. ard Strcet I AAdOO HIC R%ist!.tion Nuobcr n 11 Email tddrss Expiration D.te rwolfen com SECTION 5: WORXERS, COMPENSATION TNSURANCE AFEIDAVIT (M.c.L c. ls2. S 2sc(O) co leted a0d submitted withmp tbis Fa tolureapplication.provide o tbef permit.building AUTEONSECTIollNERoluzATIOI\i oT BE COIVIPLETDD WITENoWNER,s GENT o CORITTRA cToR A?PLIES BFOR INGUTI,I)PERITTT aU matters rclative to work authorized by tLis building pqrmit appticstio!.!o act oll Ey behslf, in Please see aftached owner auth Prifl OwtEr's Namc (Elcqronic Signaturc) I, as Owner ofthe subject plopeIty, hcreby autborize WNERlb:AUTIIORIZE ECLA.RATINsEcTto1oORDGENTADON By entering uy name betow, I he*by anest undcr the pai,s ard pen'lties of psdury that au of the iaformation coatained in this applicatiotr is tru€ and accurate to the best ofmy howledge atrd udcIshEdi!& Print Owncr's ot Agrot'r Nalnc (Elcc&onic Sig[a .c)Da(e /oZ 3-17 -22 NOTNS: hisArer arbit'atioo iaformation OrvnetAJI who abtains lo dopermitbuildhg or anwork,o}fller hireswho AE coEAactoauIrcgistercdnottheHomer€gistercd torCont'acImprovcmeot willGn haye toiK,cessc)Program),tut or flrtrd utrderprogam c.42A-thero onlmporta cHI becito AtfoondPmgnm onInJormati theoqwww.mass,qov/oca Colskuctiotr ciul fouadbe atSupervisor providc EDclosed Opcn 2. Whcn substautial work is planned,thc infonnation bclow: Total floor rca (sq. ft.)(including garage, finished basement/atticq decks or porch)Gross liviDg eea (sq. ft,Habitable room couotNumber of Nutrlber of batbrooEs Number of halflbathsType ofhealiry system l'Iuolber of deckV porchcsType ofcool.ing system "Total Prcject Squarc Foot€c,, may be substitrtcd for .,Tobl Projcct Cosf' Workcrs Compensation lrcura[ce afEdavit Eusl be this afEdavir 'f,ill rBsult itr thc dcdal of the Issuance Signed Afhdavit Arached? Ycs..........E No.....,..... tr Iti DaE 3-17-22 m tIe M.G.L.guaranty the Liceose wvrv.mass. eov/dps Number ofbe&ooms 3. $TOWN OF YABMOUTH 1146 Route 28, South Yarmouth, MA 02664 508-398-22311 ext. 1261 Fdx s08-398-0836 Office of the Builtling Commissioner BUILDING DEPARTMENT DEMOLITION DEBRIS DISPO AFFIDAVITSAL Pursuant to M.G.L. Ch. 40, S54 and 780 CMR - Section 105'3' l ' #4' I hereby certiff that the debris resulting from the proposed worVdemolition to be conducted at AO MATTAKESE RD UNIT 5 W YARMOUTII, MA 02673 Work Address Is to be disposed of oat the following location:771 Washington Street, Auburn, MA 0150'l Said disposal site shall be a licensed solid waste facility as defined by M'G'L' ch. 1ll, $150A. -tn/ Signature of lication Date PermitNo. 3-',t7 -22 The Commonweakh of Massachasefis Departmenl o! Industridl Accidcnls Office of Investigations Lafayette City Center 2 Avenue de Lafayeae, Boston, MA 02111-1750 www.mass.gou/dia Workers' Compensation Insurance Alfidavit: Builders/Contrectors/Electricians/Plumbers Anplicant Information Please Print Legibtv Name (Businesyorganizatiory'lndividual) Address: 771 Washinqton St : Solar Wolf Energy Ci tate/Zi : Auburn, Ma 01501 Phone #:-2 tAny spplicant that che4ks box f I must also fill ou! the scction bclo v showiog th.ir uo*crs' compcnsetion policy informalioo.I Hornco*ncrc who suhnit this slfidsvit indioating thay nIE doing rll wor* md th.a hirc ortsidc contracloE lnust submit a new aflidsvit indicding such. lcontraqors thst check this box must altlchcd an sdditional shc.t $owhg thc nmrc ofthc sub.colllrrrlors snd stete whethcr or nol tlrcse endties hav€ cmployecs. Ifthe sub{ontractoF havc cmployrcs, thcy mu5t povidc drcir tro*.rs' cdnp. policy numbd. I am sn e rplo!€t thol is proiding workers' compcnsalion insutancc for nE enployees, Balow ls lhe poltc! ond Job site i,tfomadon. Ilsurance Company Name: Leib lnsurance Type of projeet (required): 6. E New construction 7. E Remodeling 8. I Demolition 9. E Building addition l0.n Electrical rcpairs or additiors I l.E Plumbing repain or additions 12.! Roofrepairs otherSolar lnstallationr3.m Are you an employer? Check the appropriatc box: l. fi I am a employer with 6 4' El I am a general contmctor and I employees (full and/or part-timt* have hired the subtontractors 2. E I a; ;sole poprietor oi partner- listed on $e sttached sheet' ship and have no employies These sub{ontractors hsve woiking for me in any iapacity. employles snd have workers' [No workers' comp. insurance comp' insurance l reouired-I 5. ! \ e are a corporation and its 3. E I am a h#eorrner doing all work officers have excrciscd their myself. [No workers' cJmp. right ofexemPtion perMGL insumnci required.l t c' 152'$t(4),andwehaveno emplo)€€s. [No workers' comp. insurance rcquired.] Policy # or Self-ins. Lic. #: WC2-31 5-6 1 4936-020 Expiration Date: OBl10l2O22 Job Site Address ,1'[t Nl ldcr A Citylstate/Zip \+anro, lnA 02c13 Attsch s copy ofthe workers' compersetion policy declaretion page (showing the policy number snd expirotion drte), Failure to secure covcrage as required under Section 25A ofMGL c. 152 can lead to the imposition of criminal penalties ofa fine up to $1,500.00 and/or one-year imprisonment, as well as civil penalties in the form ofa STOP WORK oRDER and a fine ofup to $250.00 a day against the violator. Be advised that a copy ofthis statement may be forwarded to the Oftice of lnvestigations ofthe DIA for insurancc coveragc verification. I do hereby cenily undet the poins ofpeiury lhat thc inJormotioa provided aboye is lrue and conccl Ufi,* S Phone # Oflicial use only. Do nol write in this arc&,lo be complded by cil! or town olJicio| City or Towtr: permiuLice8e # ooe): Building Depsrtoeot 3.ECity/fown Cter* 4-E Ekctrist Inspcctor SDtunbilg Phone #: lssuins Authoritv (chcck rEnoa.a or xearirr zEI Insp€ctor 6.Eoth€r Conlact Persotr: 7-lz.zc LO/1 202r THIS CERTIFICATE Ig IESUED A3 A MATTER OF INFORTIATION ONLY ANO CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMENO, EXTE'ID BETmEN THE rsSUrNO TNaURER(S),. aUYHORTZEOBELOW. THIS CERNFEAIE OF INSURANCE DOES I{OT CONSTITUTE A REPRESENTAfIVE OR PRODUCER. AT{D THE CERTIFICATE HOLDER, R, THISNO RIGHTg UPON THE CERTIFICATE POLtCtESALTER THE COVERACE AFFORDED BY. tf suBRorGATtON tS WAIVED, aubr.ct to lh. l.rrnr lnd condltlon. ot thc pollcy, c..taln pollcl.. rnay rcquln an cndor..menl, A tltlem.ni on INSUREo provl.loil rcrINSURED, thc pollcy(1.3 raedca lliceta hold.r lr rn !o tha c.rtlnc.ta holder ln llou of suchthl! cortlllc.ta doa3 not coniaa 508-792-0.t11 E r'rBBRtr l(ttruAI. [rllrEElj ^Eq:ig!B 9OvEi^cE ^: TIATIIILUE tri ocjilp'CERTIFTCATE OF LIABIL]TY. INSURANCE !c:lb rDluranca 537 P.rk lv.au. xorccals!, l,tA 01503 sol,rn ror,t nlERo:I ?rl wlgErxoTolt 8T AT'BI'RII IIA COVERAGES wotKE s coFE lsarlox AIIO Ef, PLOYERS' I|ABIUIY zl AIiYPROPREiOF/PARTNEREXECUIIVEoFf tcER/l/Er/BER EXCLII0EO? CERTIFICATE NUtIBER CANCELLATION REVISION NUMBER: HOLDER CERTI4CATE EXCLUSIONS iNsuREo NAMED AaovE FoR THE PoLlcY PERtoobr tNzuaeruce usreo aELow HAVE aEEN lssuEo ro rHETHIS IS TO CERTIFY TIIAT THE POLICIES R DOCUMENT WTH RESPECT TO WHICH THISENT, TERM OR CONDITION OF ANY CONTRACT OR OTHEINOICATED. NOTWTHSTANDING ANY REOUIREM ED HEREIN IS SUBJECT TO ALL THE TERMS.THE INSURANCE AFFORDED BY THE POLICIES OESCREMAY BE ISSUEO OR MAY PERTAIN, LIMITS SHOWN MAY HAVE BEEN REOUCED BY PAID CLAIMS.AND CONDITIONS OF SUCH POLICIES. !talll EACHOCCIJRRENCE I'A[AAibt YO HTilTEbx 00r 1,000, r 100,000 s, 000 s 1,000.00OPERSONAL A AOV INJURY 2,000,000GENERA!AGGR€OAIE 2,000,000PROOUCTS . COMP/OP AGG 5 o6/0a/2or1 o6toal2022NNN1207723A or,r"-roo. [! i *" GETIT AGGREGATE LIMIT APFIIES PER:Effi ff.o" taOOltY ll{JURY {t'6tr p.,6) BODILY lltJlJFlY lFt. r@rr.^l) s HREO AUTOIOEILE I!A6ILTry scr€ouLE0 occui 1,000,000 51,000,000 1,000,000 E t OsEASE. EA olsF_asE - oe/Lo/7oa2wc2 - 31S,614936 - 020 EIICEPTIO| OF OPERATIOiIS, tocAtlotls i VETICLES IACORD rfi Arrdtdool F.drt. S.h.dd.. atv t' 'n-t'd i ifne.!.dLr.aulr4 |ftMil, tlttaolrrE rortr Blr.L 11{6 EOErr 2B fAn!firuTE PORT. lll 0265r I Th€ ACORO namo and logo ar6 r.gl.t .id io.rl(. ol ACORD N. All rlghla r.€orved .(: ! i ! tr STIU,IU) AI{Y OF TT|G AAOVE DESCRBEO POIICIES 6€ CAI{CELT.ED BEFORE rXE EXPIFAT|o DATE fttEiEof, I{OIICE wlLL BE OELryERED lr| ACCOROAIICE wlTII THE POTJCY PRO\'ISK)I{!I. ACORD 25 {zfi6103) L 5OLAR WOLF {} inc. 100 Davis Street Douglas, MA 01516 Oflice 1: (888) 8784396 Office 2: (508) 839-2222 Owner Autho rization Form We the undersigned, hereby authorize Solar Wolf Energy Inc to act on our behalf in all manners relating to the installation of a photovoltaic system at the location 80 Mattakese Rd. Unit 5 W. Yarmouth. Ma 02679 . This includes but is not limited to financing paperwork, interconnection documents, building & electrical permit applications, applicable rebate applications, etc. This atthoization is valid only for items pertaining to the installation and commissioning of a solar power system to be installed by Solar Wolf Energy Inc. Sigued under the pains and penalties of perjury. y'*qt 3. .A,rto*tt| Signature of Owner 10 1261202',1 Date Doc lD: 0a8dbfabaeb168968245a07o49e6c0ft!31cgfe Commonwealth of Massachusetts Division of Professional Licensure Board of Building R ulations and Standar., , Cons isor CS-087491 * TED C STRZFLE t Exp ires: 02119/ZAZ? 582 WAUWI BARRE MA Comrnissioner K VU,-ot* rat r / IJ; 24t7 Massachusetts of Compl*ftow. Contractors Academ Cl, A PDH Academy Company Ted Strzelecki cs-087491 hos completed the Massachusetts Contractor Classroom Renewal Course Part L Approval # CS-010212 Code Review 2 hours Workplace Safety 0 hours Business Practice t hour Energy 0 hours Lead Safety t hour Elective 2 hours o2lt7l2O22 Coordinator: Annie Schultz, Program Manager Coordinator Number: CD-000102 lf you hove any comments about this course offering, please moil them to the Boord oI Building Regulotions ond Stondords, CSL Continuing Educotion, One Ashburn Ploce-Room 7301, Eoston, MA 02708 ,% 6)*.rrorrr"o,/l /-%."*t fr"ullt Office of Consumer Affairs and Business Regulation 1000 Washington Street - Suite 710 Boston, Massachusetts 021 1 8 Home lmprovernent Contractor Registration Type: Registration: Expiration:SOLAR WOLF ENERGY INC 771 WASHINGTON STREET AUBURN, MA 01501 scA 1 6 mM-otr7 D,'/, .,,,,.,,,,,,,.= ///), 1' //. t.,.;,,, t - t z, Otffc. of CoGurn r Aff.lIs & Blr3ln .t Rlguhtlon HOME IMPROVEITIENT COiTTRACTOR TYPE: Co.DorafmReokffilon Exolref on186400 11t06t2022 SOLAR WOLF EN€RGY INC. Undersecretary Corpo.ation 186400 11106,t2022 Lrpdate Addrqss and Rotum Card. Registration valid ror lndividual uso only bstoro tho expiration dalo. Itfound rolurn to: Otfica of Consumer Affairs .nd Businoss Rogulrtion 1000 Washlngton Shoet - Suite 7'10 Boston, MA 02'118 TED STRZELECKI 771 WASHINGTON STREET AUBURN, MA O15O,I k-ta.1L,r*,Not valid without signature SOLAR WOLF 771 Washington Street Auburn, MA 01501 Toll Free: (888) 87E4396 www.solarwolfenergy,comrnc. Home Improvement Contract Sales Consultant Joe Antonelli 80 Mattakese Rd Unit 5 West Yarmouth, MA 02673 (617) 308-5558 Jfantonell i@comcast.net Yasmene Badereldin 771 Washington Street Aubum, MA 01501 (508) 583-9451 Yasmene.b@solanvolfenergy.com System Information System Size: 8.04 Cunent Annual Electic Use (kWh): 8,667 Inverter Manufacturer: ENPHASE lQ 7+Module Make & Model: SUNPOWER 335 Module Count: 24 lnverter Count: 24 Include l0 Year Online Monitoring:YES NO Cormection method ifnot standard offering: Elecrical Panel Upgrade: YES RoofReplacement: YES Tree Removal: EYES ENo Howmany: AgttlB$"US8%pprovat for sotar from HoA o o Total Project Cost ($):20 824 Financed Amount: ($): N/A oJDift.at rho Tori C!d): Loan Term: N/A Cash Payment Schedute (Not Applicable IfFinancing): N/A Interest Rate (%): N/A Customer Initial Customer tritial Customer lnitial Customer Initial Payment Method: Finance Company: Cash lFinarce 30% Due at Signing ofContract + 30% Due at Filing of Permits 30% Due at Start of lnstallation l0% Due at System Commissioning s6 247.20 $6 247.20 s6,247.20 s2,082.40 *(it tial deposit not to exceed l/3 ofthe Contract Price or the cost ofspecial-order items, whichever is greater). A failure to make payment for a period in excess of teD (lO) days ftom the due date shall be deemed a material breach of this Contract. tt payment is not made when due, Contractor may suspend work on the job until such time as all payments due have been made without breach ofthe Contract petrding payEent or resolution ofany dispute. Owners wiil be responsibte for any and all costs resulting from the delays or stoppage including but not limited lo any increase Ooc lO I ae223 1232a2c2bgd b 1 46e9e656b3f 5261 3a429 I 3 NERGY Contact Information Customer Name Address City, Stete, Zip Phone Email PAYMENT INFORMATION Years I cost of subcontractor stoppage and remobilization, potontial need to replace contracts and increasos in overhead costs to Coatsactor, Owner(s) shalt pay Contractor htsrest at the rute ofotre and one-halfperceDt (1.50%) per month on tbe total portion of the price that remains unpaid seven (7) days or more after the date Won whicb paymeot is due. If the Owne(s) refuse to pay for any prcgress paymeDt which is more than 30 days past due, the Owne(s) shall be deemed in breach ofthis Agreement and lhe Cont'actor may stop wort at aoy time and recover the amoutrts owed and shall be etrtitlcd to rccover its costs ofcollection, including its reasonable attomey's fees. Ifowner does not pay auy podiotr ofsaid coDtract, OwDer agrees to forfeit any and all solar incentives and agrees to award them to Solar Wolf Energy. If alt payments are not receiyed, Solar Wolf Energy reserves the right to disconnect the solar aray until all payments are brought curent. PROPOSED START DATE AND END DATE: The Scope of Work shall commence on or about 12122121 . Contactu will not begin the Work or order materials befors the third day following the signing ofthis Agreement, unless specified in writing. The commoncement dat€ is subject to permit and variance issue dates, completed architectural &awings and specifications. All installation schedules are weather permitting. Should snow, rain, win4 or cold weather coincide with scheduled installation day, the installation will be moved to the rext date available. Any contsact sigued after Septembe. lst is susceptible to weather conditions and may not guarantee installation before year end. SOLAR WOLF The Work shall continue on a substantially complete on 01 regular basis except t22t22 for delays beyond the Contractor's control and is anticipated to be Contractor agrees to keep Owrer informed of any delays that may interfere with substantial completion within the estimated poriod set out above. The Contractor shall not be liable for any consequetrtial, incidental, delay, emotional distess or contingent damages arising from this Contract. Nor shall the Owner reduce or holdback funds in the event of, auy delay or nonperformance caused by natural disasters, pandemics, acts ofGod, strikes, shortages of labor or materials, holidays, delays caused by comptetion of other jobs, detays in delivery of items selected by the Ownel inclement weather, accideuts, alterations or modifications agreed to by the Owne(s), delays caused by the Owne(s), delays by state or municipal govemmental offices, "Hidden Conditions" or any other contingency beyond the Contractor's contol. h additio[ to atry other extensions provided for in this Agreement, Coots'actor shall receive a reasonable exteNion of time to commence and./or complete its Work hereunder following the cessation of any delay and such extension shall be set forth in a written change order In the eyeot the Contsactor is unable to complete the performance of its obligation under this Ageement due to acts of God, strikes, unavaitability of supplies or materials, or any other contingency beyond its coDtrol after 30 days, either party may cancel this contracl, ir which eyent the Owner(s) shall be liable to pay the Contractor the amoutt of labor and materials already firmished as well as reasoDable profit and overhead. Such paymsnt is to be made within seven (7) days after the date of such cancellation. PERMITS: The Contractor, under provisions of M.G.L. c. l42A is required to apply for and obtain all constuction- related permits. Contractor shall obtain all permits required by government bodies, unless otherwise specified, as the Owne(s) agent. The cost of said permits witl be part ofthe Cost of Work as defined herein and charged to Owner(s). Owner(s) who secure th€ir own coDstructiotr-relsted permlts or derl wlth utrregfutered cotrtrsctors shall be ercluded from access to the Gurratrty Fund proyisiotr of M.G.L. c. 142A. The Owneds) shall obtain and pay for the necessary approvals, easements and/or variances required for tho Project. Said costs arc not iocluded in the total Agreement Price. ACCESS TO PROPERTY: The work camot proceed until this agreement has beeD fully signed and executed by both parties. Unless it is otherwise specified in writing herein, it is undersrood that the Owner is ready for this work to begin. Owner shall granl access to contractor, its ag€nis, representativas, and authorized subcontacton and vehicies, A refusal to permit the CoDtractor or its representatives to proceed with the work herein will be deerned a brcach of this agreement. 7 $4ffiffiffiY inc. 771 Washington Street Auburn, MA 01501 Toll Free: (888) 8784396 www.solarwolfenergy.com Doc ll ae2231232a2c2b9d b 146e9e656b3f526'l 3a4291 3 SOLAR WOLF 771 Washington Street Auburn, MA 01501 Toll Free: (888) 878-4396 www.solarwolfenergy.comlnc. The Owner or the Owuer's reproscntative must be at the prop€rty during all installatiou work and has full authority to make decisions on the Owner's behalfshould any problerns arise. This includes but is not limited to module placemeot, wire maoagement, equipmenl management, and more. If the Owner is financhg the system, the Owner agrees to be prcsent for the duation ofthe installation to sign the frlancing completion ceftificate upon completion ofthe work. If the completion certificate is not sigoed upon completion ofinstaltation, final inspections will not be scheduled. Owner authorizes Contractor the right to display signs and advertise at the job site ftom date of execution of this conEact and contiruing until 60 days after completion. CIIANGE ORDERS: Upon reasonable request of Ownels, Contactor may, at Contractor's sole discretion, make changes, additions, or alterations of thc Work, and the Contract Price and Substantial Completion time will be modified and set out in a vritten Change Order signed by both Owners and Cootraclor. Such Chaage Orders shall become part of this Conhact. OwneIS agrees to pay any increase in the cost ofthe Projcct as a result ofa Change Order. In the event the cost of a Change Ordsr is not knontr at the time a Change Order is executed, the Contractor shall estimate the cost thereofand Owners shall pay the actual cost \vhether or not it is in excess ofthe estimated cost. Owners agree to make r€quests coucarning any changes, additions, or alterations in the Wo*, dfuectly to Contactor and not to worken, including subcontractors, on the Work Site. Change order work will be bitled at $ 120 per hour plus materials and will be due at the time of final invoice. Ifthe Owne(s) refuse to pay for any Change Orders by the payment due date, tho Owne(s) will be deemed in breach ofthis Agreemest and the Contractor may stop work at any time and recover the amounts owed ard shall be entitled to recover its costs ofcollection, including its reasonable attomey's fees. Aly increase in the Scope of Work set forth in this Agreem€ot \trhich is required by plan checkers or field inspectors with city or county building/ptarming deparknents or requLed due to any "Hidden Conditious" as defined below, will be treated as additional work to this Agreement for which the Contractor will issue a change order. If auy structural upgrades are deemed necessary by a third-party engineer, there will be an additional cost assessed, discussed and agreed upon with the customer. Prices may also fluctuate du€ to govemment-enforced tariffs. Any increase in the cost of materials of ten (10%) or more from the date the coDtract is signed, shall entitle the Contractor to issue a change order that increases tho Contact Price. LEDGE OCCITRRENCE (GROUND MOUNTS): This agreemcnt does not include an amount to be assessed tor the presence of ledge. Ledge is ideutified as atry rcck that is larger than I cubic yard in sizo. Ledge will impact cost and time since with groud mounts, the [oed to excavate the material is unseen and underground. If ledge is discovered, it will be shown to the Owler alld a cost estimate for its removal will be made at that time. IIIDDEN OR UNFORSEEN CONDITIONS: The parties hereby aclnowledge that in certain remodeling work, the demolition ofportions ofthe pre-existing structurc may reveal additional defecs, conditions or the need for additional work that could not have been identified by Conhactor with reasonable diligence ('Hidden Defects") which must be repaired, allercd or caried out in orde! to commence or to complete the Scope of Work. Further, as result of such Hiddel Defects, the Substalrial CompletioD date and total A$eement price may need to be modifie.d. Any additional work required will result in the issuance ofa written change order. The parties agree such modifications are not avoidable and shall not be considered a breach ofthis Ageem€nt. 3 D oc lO : ae223 1 232a2c2 bgdb 1 46ege656b3f 526 1 3a429 1 3 ENERGY Solar Wolf Energy is not responsible for any pre-existing conditions that are not in compliance with applicable building and energy codes. Any necessary upgrades are the sole rosponsibility ofthe Ownet. ONLINE MONITORING: For online monitoring, Sola. Wotf Energy uses the SolarEdge, Sunpower, and factory provided cellular kits with all installations. This deviae updates every two to six houls. IfOwner requests a dtect w e SOLAR WOLF 771 Washington Street Auburn, MA 01501 Toll Free: (888) 878-4396 www.solarwolfenerry,comrnc. or any difTerent typo ofconnection, there will be an additional time and material chargo. Solar Wolf Energy reserves the rights to the online monitoring platform until final payment has been received from the Owrer. Upon receipt, Solar Wolf Energy will release the online monitoring platform !o the Owner- INSURANCE; The Contracto! agrees to carry liability insurance as is necessary to protect the Contractor, hN employees, subcoDtractors and the Owner(s) from claims for bodily injury, including death, which may arise from the performance of this Agreement by the Contractor. The CoDts'actor hereby warrants that all employees and subcontractors under its supervision performing Wo* at the Premises are covered by workels' coEpeDsatioD insuance. Conhactor shall fumish certificates of insurance !o Owne(s) upon request. The Owner(s) will purchase, effect and maintain property insurance for all rhe Work to be performed under this Ageement. The policy shall be a Homeowner's or Contractor's Risk type on a replacement cost basis, "Special Form." The policy shall be equal to the full insuable value of the Work. The coverage shall not necessarily extend !o tools and equipment of the Contractor, subcontractors ofany tier, or property owned by employees ofany ofthem, vehicles of any kiud, or drawings or specifications. However, the Owner(s) agree to use ordiBry care in the storage of tools and equipment of the ConFactor, subcontractors of any tier, and job materials and supplies located on the Premises for the duration of this Project. This lnsurance shall include the intercsts of the bank, or other mortgage holder, if applicable, and the Owner shall insure against "all risks" ofphysical loss or damage. In addition to Owner(s) usual property and liability insurance, Owne(s) agreo to carry insurance in amounts sufficient to cover claims, of any nature, arising out of or relating to existing or newly constucted stuchles, or any portions thereol Said insurance shall also include, but is not limited to, coverage for materials and fixtures, delivered, installed, placed or erected at the Premises or at aDy temporary locatioD. Such insurance shall provide complete replacement for damaged or lost property due to fire, theft, vandalism and all "extended perils." 4 ARBITRATION The Cotrtractor aod the Owne(s) hereby mutually agree in advance that in the event that oue ofthe parties hereto has a dispute conceming this Agreement, eithor party submit such dispute to a private a$itration service which has been approved by lhe Office of Consumer Affairs and Business Regulation and the other party shall be required to submit to such arbitration as provided in MGL c.l42A. To the fultest extent permitted by law, each ofthe parties hereto shall be eDtitled to have any claims against it decided in arbitration, cven ifone party initiates an action in the couts. In such event, at either party's option, the cout action shall be stayed white the matter is decided in a6itration. The prevailing party in any arbitration may petition a Court of competent jurisdiction for enforcement of such decision. As loug as both parties agree, they may at any time and without cotrsequence opt out of this Arbitatioo agre€ment aod seek redress in any cout of competeot jurisdiction. Notw.ithstanding the foregoing, to the fullest extent permitted by law any controversy or claim arising out of or related to this Agreement irvolving an amount ofless than $?,000 (or the maximum limit ofthe court) may be heard in the Small Ctaims Division of the Municipal Coun io the couoty where the Premises are located and judgment upon au award in Small Claims Court may be entered in any Court having jurisdiction thereof. NOTICE: The signatures of the parties apply only to the agreement of the parties to altemak dispute resolution initiated by the Contactor. Thc Owner(s) may initiate altemative dispute resolution even \i,herc this section is not signed separately by the parties. We, Solar Wolf Energy, Inc. and the Owner(s), have read the above Arbitration Agreemetrt aDd understand its tsrms and both have signed it as our froe act and dsed. D oc lg : ae2231 232a2c2 b9db 1 46e9e656b31526 1 3a429 1 3 SOLAR WOLF 771 Washington Street Auburn, MA 01501 Toll Free: (888) 8784396 www.solarwolfenergy.com y'u,7t 3 C,,t,"l,09t27 12021 Owner Name Datc Owner Name Sales Name COVII)-Tg RELATED CLAUSES Date 09 t21 t2021 Date The Parties acknowledge that the ongoing COMD-t9 cpidemic,/pandemic and the evolving situation surrounding the same may friggor stoppages, hindrances and/or detays in Contsactor's (or its subcontractors' or suppliers') ability or capacity to perform the coDtacted work and/or io produce, deliver, install or service any applicable products, irrispective of whether such stoppages, hindrances aud/or delays are due to measures imposed by authorities or deliberately implemented by Cotrtactor (or its subcontractors or supplien) as preventive or curative measures to aYoid haruirt contaminatioD or exposure of Contractor's (or its subcoukactors' or suppliers') employees. The Parties therefore recognize that such circumstances shall be considered as a cause for excusable delay and shall not expose Contractor to contBctual sanctions (including u.ithout limitation delay penalties, liquidated damages or other damages) or temination for default, provided that Conhactor shall take all reasonable efforts to mitiSate such delays or impacts. Should the Contractor be delayed, obstructed, hindered or interfcred with in the cornmcBcemetrl, prosocution or completion of the Work by any goyernmental directivc or order in no way chargeable to the Contractor, or_by any extraordinary conditions arising out of war, govemment rcgulations, state o! national emergency, global health pandemic, additional health or safety regulations, or by any other cause beyond the costol of and not due to any fault, aeglect, act or omission ofthe Coutractor, its officers, agetrts, employees, subcontsacton or suppliers, then ConEactor shall be entitled to atr extension of time. Contractor remains responsible for compliance with atl applicable federal, state and local laws, rules, regulations and guidance invotving health and safety, includiog, but not timitod to, those la\vs, rules, regulations and guidance issued by the Center for Disease Control, OSHA and other fedeBl, state and local govemmentsl authorities in responsc to COVID-I9. This includes, but is not timited to, implementing social distancing measures and acquiring, providing and property using any personal protective equipment, as uraadated by fedsral, state and local laws. Contactor shall impGment such safety measuies to fight the spr€ad ofCOVID-19 during the entire duration of the Project without additional compensation. The parties waive all claims for Eansmission of COVID-I9 against each other. RIGHT OF CANCELLATION: Owner(s) may cancel this A$eement at any time prior to midnight of the thtd business day after the date ofthis transaction. Such cancellation must be done in writing by executing the Notices of Cancellation attached hereto. The Contractor may thereafter recover the cost of all uupaid labor aDd materials for all Wort incoryoruted into the Project (whether invoiced or not) plus reasonable overhead and profit. OWNER'S RIGHT TO REGISTRATION INQUIRY: Subjoct to certain exceptions, all home improvement conts.ctorc and subcontactoE shall be registercd and any iqquiries about a Contractor ot subcontractor relating to a rcgist'ation should be directed to: 5 D oc lD : ae2231 232a2c2b9db 1 46ege656b3t 526 I 3a429 1 3 ffiNE l{GY inc. /44,- !rt!I\!T EV ENGINEERS projects@evengineersnet.com http://www.evengineersnet.com 276-220-0064 03/2u2022 RE: Structural Certification for lnstallation of Residential Solar JOE ANTONELII:80 MATTAKESE RD U-5, W, YARMOUTH,MA 02573 Attn: To Whom lt May Concern This Letter is for the existing roof framing which supports the new PV modules as well as the attachment of the PV system to existing roof framing. From the field observation report, the roof is made of Asphalt Shingle roofing over roof plywood supported by 2X4 Rafters at 24 inches. The slope of the roof was approximated to be 28 degrees. After review of the field observation data and based on our structural capacity calculation, the existing roof framing has been determined to be adequate to support the imposed loads without structural upgrades. Contractor shall verify that existing framing is consistent with the described above before install. Should they find any discrepancies, a written approval from SEOR is mandatory before proceeding with install. Capacity calculations were done in accordance with applicable building codes. Design Criteda Code Risk catesorv Roof Dead Load PV Dead Load 201s rRc (AsCE 7-10)-CMR 780 9th Ed I Dr 10 psf DPV 3 psf Lr 20 psf S 30 psf Roof Live Load Ground Snow lf you have any questions on the above, please do not hesitate to call. STRUCT ONL Sincerely, VINCENT MWUMVANEZA ctvfl- $oF rh Wind Load Vincent Mwumvaneza, P.E. EV Engineering, LLC proiects@evenPineersnet.com http://www.evengineersnet.com (component and Cladding) V 142 mph Exposure B TtI EV - ENGINEERS projects@evengineersnet.com http://www.evengineersnet.com 276-220-0064 Structural letter for PV lnstallation This Letter is for the existing roof framing which supports the new PV modules as well as the attachment of the PV system to existing roof framing. All PV mounting equipment shall be designed and installed per manufacturer's approved installation specifications. Table of Content Sheet Cover Attachment checks Snow and Roof Framing Check Seismic Check and Scope of work EngineerinB calculations 5ummary Risk category Roof Dead Load Dr PV Dead Load DPV 1 2 3 4 ll 10 psf 3 psf Roof Live Load Ground Snow Wind Load References Lr 20 psf S 30 psf (component and cladding) V 142 mph Exposure B Vincent Mwumvaneza, P.E. EV Engineering, LLC proiects@evengineersnet.com http://www.evengineersnet.com VINCENT MWUMVANEZA ctvtt 7/7 03/27/2022 Job Address: 80 MATTATESE RD U-5, W YARMOUTH,MA 02673 Job Name: ,OE ANTONEtLI Job Number: 22O32UA Scope of Work NDS for Wood Constructioo Sincerely, - !I!I EV ENGINEERS projects@evengineersnet,com http://www.evengineersnet.com 276-220-0064 Wind Load Cont. 1.00 28.0 Degrees I ASCE 7-10 Table 1.5-1 ASCE 7-10 Fiture 26.5-1A ASCE 7-10 Sec 26.7.2 ASCE 7-10 Sec 26.7.3 ASCE 7-10 Sec 26.8.2 ASCE 7-10 Figure 30.5-1 3.60 ft ASCE 7-10 Figure 30.5-1 Where a: 10% of least horizontal dimension or 0.4h, whichever is smaller, but not less than 4% of least Risk Category = Wind Speed (3s gust), v = Roughness = ExPosure = Topographic Factor, Kn = Pitch = Adiustment Factor, l = Pnet30= Pnet = 0.6 xIx KZT x Pnet3o)= Raft er Attachments: 0.6D+0.6W (CD=1.61 14, mph B B horironteldimenrion or 3ft (0.9m) Upltft l0.6wl Pneulo= Pnet = 0.5xlx KZT x Pnet3o)= Downp.essu.e 10.6W) Zone 1 (psf) -30.2 18.10 Zone I (ps0 33.0 19,80 zone 2 (pso -35.3 21.* Zone 2 (prfl 33.0 19.80 zohe 3 (pso -36.3 21.m zone 3 (psf) 33.0 19,80 4ft 266 lbs/in 2.5 in r.4 760 Flgure 30.5-1 Equation 30.5-1 Fi8ure 30.5-1 Equation 30.5-1 Table 12.2A - NDs DFL Assumed Connection check Attachement max. spacing= Lag Screw Penetration Prying Coefficient Allowable Capacity= tl7 0.6OrO.6W DpYr{.6W zone Tdb wldth Area (ft} upllft (lbs) Down (lbsl 7 4 11.0 779.3 250.8 2 4 11.0 220.0 250.8 3 3 8.3 165.0 188.1 Max= 220.0 < 750 ootu{EcfloN ts oK 1. Pv seismic dead weight is negligible to result in significant seismic uplift, therefore the wind uplift governs 2. Embedment is measured from the top of the framing member to the tapered tip of a lag screw. Embedment in sheading or other material does not count. 5/16" Lag Screw Withdrawal Value= -t I\!I EV ENGINEERS 276-220-0064 Vertical Load Resisti De Roof Framing Pg= 30 psf ASCE 7-10 , Section 7.2 fu= Ce= 0.9 ASCE 7-10, Table 7-2 prr n. = q = 1.1 ASCE 7-10, Table 7-3 pr = l" = 1.0 ASCE 7-10, Table 1.5-1 c5 Max Length, l, = 5.0 ft Trlbutary Width, Wr = 24 in Dr = 10 psf 20 plf PVDL= 3 psf 6 ptf Load Cas€; DL+0.5W Pnet+ Ppvcos(0)+Por= 65.6 plf Max Moment, M, = 262 lb-ft Conservatively Pv max Shear 250.8 lbs Max Shear, Vu=wU2+Pv Point Load = 329 lbs load Gse: Dt+0.75(0.6W+Sll 0.75(Pnet+Ps)+PFcos(0)+P0,.= 81plf Moo*n= 325 lb'ft Mallowable = 5x x Fb' (wind)= 704 lb-ft > 325 lb-ft 21 psf 25.0 psf 25 psf o.7 o( ps+ po,cos(0)+por= Mao,n= Mallowable = Sx x Fb' (wind)= 60 plf 241 lb-ft 506 lb-ft Member Capacity DF-L No.1 2X4 Design Value cr cr ci c,KF 0 T Fr=1000 psi 1.5 1.0 1.15 2.54 0.85 0.8 1725 psi 180 psi N/A 1.0 N/A 2.88 0.75 0.8 180 psl E=1700000 psi N/A 1.0 N/A N/A 1700000 psi Emln =620000 psi N/A N/A 1.76 0.85 520000 psi Depth, d = Width, b = Cross-Sectonal Area, A = Moment of lnertia, lo = section Modulus, so = Allowable Moment, Man = Fb'SE = Allowable Shear, V"|= 213F,'A= 3.5 in 1.5 in 5.25 in 5.35938 in 3.0625 in 2 4 3 DCR=M"/Mar = DCR=V,,./Var = Satisfadory Satlsfactory 0.45 < 1 0.52 < 1 717 projects@evengineersnet.com http://www.evengineersnet.com 3s.0 plf load Case: DL+S > 247 lb-ft OK Max Shear, V,=wU2+Pv Point Load = 329 lbs Rafters Adiusted Value 1.0 1.0 440.2 tb-ft 630.0 lb E l,i,o,,urr*,pro.iects@evengineersnet.com http://www.evengineersnet.com 276-220-0064 Siesmic Loads Check Roof Dead Load 10 psf % or Roof with Pv Dpv and Racking Averarage Total Dead Load lncrease in Dead Load 26% 3 psf 10.8 psf 3.1% Ol( The increase in seismic Dead weight as a result of the solar system is less than 10% of the existing structure and therefore no further seismic analysis is required. Limlts of Scope of Work and Liabiliv 7/7 We have based our sructural capacity determination on information in pictures and a drawing set titled PV plans JOE ANTONELLI. The analysis was according to applicable building codes, professional engineering and design experience, opinions and judgments. The calculations produced for this structure's assessment are only for the proposed solar panel installation referenced in the stamped plan set and were made according to generally recognized structural analysis standards and procedures.